Termination and Making Time of the Essence

What can a party do if there are delays to construction works? Is there any consequence if you demand that those works are completely urgently? This particular problem came up in the case of Sunshine Ventures Limited & Rashmith Thakar v Hussein - [2009] EWHC 2866 (QB)

The Facts:

Sunshine Ventures owned a nursing home and one of its directors, Rashmith Thakar owned a flat. Both parties engaged Kurdeih to carry out work to the nursing home and the flat. There was very limited documentation. Disputes arose regarding delay and completion of the work as well as the making of interim payments to Kurdieh. Thakar demanded that outstanding work be completed as a matter of urgency. Two months later, the work to both the nursing home and flat was terminated by the claimants. At that time, the work had not yet been completed.

The Issue:

Was the claimant entitled to terminate the contract on the basis of its demand that the work be completed urgently? In other words, had the claimants made "time of the essence" such that could terminate the contract.

The Decision:

Judge Seymour QC held that the claimant's notice was not sufficient to make time of the essence. The claimant should have provided a clearer indication of what was supposed to be completed and by when. It also had to state that if it was not complied with then the claimant would treat the contract as coming to an end. Further, they had to specify a reasonable time for compliance.

As the notice was invalid, the claimants had wrongfully repudiated the contract. The claimants were therefore in breach of contract.

In addition, the Judge stated that an employer under a building contract could not complain that some parts of the work were defective before completion of all of the works. The contractor had to be given an opportunity correct or complete work, at least until the stage where all of the works was substantially completed. It was also well known that minor disconformities were remedied during the final stages of a project under the heading "snagging".

Comment:

It is not unusual for owners to become frustrated once a...